Kunzweiler v. Lehman

The plaintiff was a contractor, and one Hatfield the owner of a building in which the plaintiff agreed to make certain alterations. The defendant guarantied the performance of the contract, on the part of Hatfield. The repairs were to be completed within 40 days. Eight days after the expiration of the time for completion, Hatfield terminated the contract, and completed the building himself. The roof was not embraced in the plaintiff’s contract. The plaintiff showed that the roof remained in such condition, from the neglect of Hatfield to have it completed, that work which he was to do could not be done, and the jury found that the plaintiff was not re

Whatever effect the failure to complete the contract within the time prescribed, and the variations from the contract in the performance of the work, may have had upon defendant’s rights as surety, I think he has waived them by his failure to plead that defense. His answer admits the making of the contract as claimed by plaintiff, and his own guaranty. The substance of the further allegations of the answer is that Hatfield had a right to terminate the contract and prevent the plaintiff from doing further work thereon, because plaintiff had failed to perform according to the terms of the contract. TMs admitted proof as to how much had been done under the contract, and whether it was completed or not, and whether Hatfield had the right to terminate it, all of which questions have been passed upon under the verdict of the jury. Incidentally, testimony pertinent to that issue disclosed what the defendant now claims relieved him from responsibility under his guaranty; but,with out an affirmative defense alleging that he was relieved because of the variation of the contract which he guarantied, I do not think he is entitled to that relief. The variation of the contract between plaintiff and Hatfield was new matter, which, if it arose at all, arose after the execution of the guaranty by defendant. Defenses arising after a contract has been made constitute new matter, -which must be pleaded. Code Civ. Proc. § 500; St. John v. Skinner, 44 How. Prac. 198; Weaver v. Barden, 49 N. Y. 286 . The defense that a surety is discharged by an extension of time given to the principal must be interposed by answer. Hubbard v. Gurney, 64 N. Y. 457 . In commenting upon whether or not a surety under a building contract was relieved by changes in the contract, the court, in Henricus v. Englert, 137 N. Y. 495 , 33 N. E. 550 , says, “We may also notice that the defense.that the defendant, as surety, was discharged by changes in the contract, was not set up in the answer.” The defendant, therefore, is not in position to claim that the plaintiff and Hatfield varied the contract in such manner as to relieve him from responsibility.

But, in addition to this failure of pleading, I think that there was no such change in the contract as to relieve the defendant from his liability as surety. With respect to not completing the work within the time specified in the contract, the proof showed, and the jury found, that the-plaintiff urged Hatfield to repair the roof so that he could complete his contract within the period, and that Hatfield neglected to do it. The plaintiff is not responsible for such acts of Hat

“If the plaintiffs had in any way been a party to those changes and alterations of the contract, the defendant would have peen in a position to claim (Whether successfully or unsuccessfully, we do not determine) that he was discharged from the obligation of his bond as surety for Vogel. But it is impossible to perceive how any action of Vogel, or of Vogel and the architect, could deprive the plaintiffs of their right to enforce the obligations of the bond against the defendant.”

Hatfield neglected to put the roof, which was not included in the plaintiff’s contract, in proper condition so that the work might be progressed. Therefore it does not relieve the defendant from responsibility because the plaintiff did not complete his contract within the time limited. Nor do I think such changes as were made in construction relieved the defendant from liability. The most material change was in the glass front and doors of the building. The jury found by their verdict that the architect employed was the'architect of Hatfield. This architect gave the plaintiff a detailed plan of the front of the building and the doors, and directed the construction according to that plan. This was the principal thing that Hatfield complained of. He denied that the architect was employed by him, or that- the detailed plan was one furnished by the architect. The proof is overwhelming upon this point. The plaintiff- was not responsible because the front and doors, constructed according to this plan, did not please Hatfield or fit the building. Whatever the architect did was the act of Hatfield, and the defendant was not relieved because the plaintiff' did what the architect directed. The plaintiff was not a party to any changes in respect to the front differing from the contract; and, as-was said in Henricus v. Englert, supra, it is impossible to perceive hów any action of Hatfield and the architect could deprive the plaintiff of his right to enforce the obligation of the defendant. I cannot subscribe to the doctrine that the surety was relieved by the other minor changes in the contract which were made in the course of the répairs to the building. The only thing of importance was the fact that the plaintiff and .Hatfield agreed that the plaintiff should put deafening for tiling in a certain floor not embraced in the contract,. ' instead of laying a floor in the water-closet, as provided by the contract. The one work was substituted for the other. No charge was made for it. It was all considered as being under the contract, and while the contract of a surety is a strict one, and he is bound only to-respond to the contract which he actually guarantied, yet such a change in a building contract I do not think operates to relieve the surety. ' It might as well be said that if the owner desired two panes of glass in a window, instead of four, which the contract called for,, an acquiescence by the contractor in his wishes, and the putting in of the two panes instead of four, would relieve any bond or guaranty

Motion denied.