Elting v. Dayton

Headnote

Pleading — Amendment.

In an action on a building contract the complaint alleged performance. The referee found that the work was not completed within the time agreed, but that defendant had cmsed the delay and had waived strict performance and gave judgment for plaintiff which was reversed on appeal because of the variance between the pleading and proof. Held, that the plaintiff should be allowed to amend the complaint by alleging such delay and waiver on payment of costs of the reference and appeal. ,

Appeal from order denying leave to amend the complaint.

February 25, 1885, the plaintiff, a builder, entered into a contract with the defendant, the owner of five houses, to repair them, according to plans and specifications, for $9,726, on or before April 20, 1885. The work was not in fact completed until May 15, 1885. The defendant paid towards the contract price, March 25, 1885, $2,000; April 10, 1885, $2,000; May 8, 1885, $2,000. August 25, 1885, this action was begun to recover $3,726, the remainder of the ■ contract price, and $500 for extra work, which was set up as a first cause of action. In the first count the plaintiff averred that he had performed his' contract As a second cause of action, it was alleged that Hart.Z. Norton had done work and furnished materials for the buildings for which the defendant, promised to pay $600, and that the claim therefor had been assigned to the plaintiff, who demanded judgment for $4,826. The defendant admitted the making of the contract with the plaintiff as alleged, and that he had paid $6,000 thereon. He denied that, the plaintiff had performed his contract, and also denied that he was indebted in the sum of $500 for extra work. The defendant, further denied that he had made a contract with Norton, and was indebted on account of work performed thereon in the sum of $600. As a second defense, and as a counterclaim, the defendant averred that the plaintiff had not performed his contract in a good and workmanlike manner, and had failed to complete it within the time limited, to his damage in the sum of $2,500, for which he demanded judgment. The case was tried before a referee, who found that the work was not completed within the time agreed, but that the delay was caused by the defendant’s ordering additional work, which was performed by the plaintiff, which was worth $440. He also found that. Norton had, under his contract, done work for the defendant at the agreed price of $600, and that the claim had been assigned to the plaintiff. He disallowed the defendant’s counterclaim, and ordered a judgment for the plaintiff for $4,766, which was reversed by the general term, and a new trial granted.

The reversal was placed on the ground that, the plaintiff having alleged performance,, and not having averred an extension of time therefor, he could not, as against the objection and exception of the defendant, without amendment of the complaint, recover on the theory that strict performance had been waived. Biting v. Dayton, 43 St. Rep., 363 . After the new trial was ordered, thé plaintiff moved at special term for leave to amend his complaint, by averring that he was prevented from performing his contract within the time limited by reason of the additional work ordered and required, and that defendant had waived the completion of the work within the time mentioned in the contract.