Snow Mountain Water & Power Co. v. Kraner

The defendant was engaged in the work of constructing a large cement dam for the plaintiff under a contract by the terms of which, in the event of abandonment of the work by the contractor, plaintiff might take over all tools, equipment, and supplies of the contractor and proceed to complete the structure. Alleging that the defendant had notified it that he declined further to proceed Avith the performance of his contract and was about to remove the equipment from the work, plaintiff brought this suit to restrain such threatened action. A restraining order was granted, and by stipulation was continued as a temporary injunction. Defendant took the position that the contract had been terminated by an act of the plaintiff. He filed counterclaims and a cross-complaint for the recovery of $873,625, alleged to be the balance due for the reasonable market value of all of the work done at the dam, after crediting plaintiff >vith the sum of $1,060,825 paid, computing said balance on the basis of the cost of all the work done plus ten per cent. The trial court found that the defendant had in fact abandoned the contract. Judgment was rendered against the defendant on his counterclaims and cross-complaint, and plaintiff was awarded its costs. No order was made for the continuance of the injunction, since plaintiff had completed the construction of the dam before the determination of the action. This appeal by the defendant folloAved.

On December 15, 1919, the plaintiff entered into a contract with the defendant for the construction by the latter of a concrete dam across the South Eel River, on a site mentioned in the contract, at the loAver end of Gravelly Valley, in Lake County. According to the plans and specifications, the work was to be done within certain delineated and designated lines extending from the north to the south bank of the stream. Prior to entering into the contract, defendant, with his engineers, made a thorough investigation of

“The Company shall have the right to make, but only by orders in writing, such reasonable alterations, omissions, additions or substitutions in said plans and specifications as the Company may deem necessary. The Contractor agrees to accede to and carry into effect all such alterations, omissions, additions or substitutions as though they were originally provided for in this contract.

“In the event of such alterations, omissions, additions or substitutions increasing or decreasing the cost of constructing the said dam there shall be added to, or subtracted from, the amount which the Company has agreed hereby to pay to the Contractor for the entire work, a sum equal to the difference between the actual cost of the materials and labor entering into such alterations, omissions, additions or substitutions, but not including any portion of the time of the superintendent or office employees, or overhead expenses, except industrial insurance, plus twelve and one-half per cent as the Contractor’s profit, and the same cost estimated in the same way of the work or construction which would have been done under the plans and specifications made a part of this contract, had there been no such alterations, omissions, additions or substitutions.”

It was stipulated in the contract that the defendant should begin work not later than January 1, 1920, and should have all concrete poured and the dam ready for use in storing water on or before December 1, 1920, and all additional work done and the dam entirely completed on or before February 1, 1921. Immediately upon the execution of the original agreement the defendant commenced the work of constructing the dam. The state Railroad Commission exercised jurisdiction over the work, paying particular attention to the exposure of satisfactory foundations for the construction of the dam before any

Defendant’s original plan of work was to build the dam from both banks of the river toward the center, but work was prosecuted more diligently on the north end of the structure than on the southerly side. The trial court found that the delay in completing the work at the,southerly end of the dam was not caused by any acts of the plaintiff. The real reason for the concentration of work on the northerly end of the structure seems to have been that work at that point was done more easily, and that the pouring of cement could progress more rapidly. The defendant testified that he expected the progress payments at five dollars a cubic yard for concrete poured to carry the expense of the work. When defendant finally began work of excavation for the foundation on the south side of the river, difficulty of construction was experienced by reason of the nature of the ground. On October 28, 1920, the axis of the dam was accordingly changed, so that from a point about 590 feet from the northerly end of the structure it would be constructed at an angle of 32 degrees from such point to a large boulder 75 feet high lying on the south side of the river. Defendant was directed to make this change, and to construct a ring of cement and a cutoff wall under the boulder and into the hard rock beyond. This change was considered a more economical and quicker way of building the dam than by completing it on the straight line axis, because of the nature of the ground and the material to be moved. Defendant accepted

In view of the changed conditions created by the floods, plaintiff verbally ordered the defendant to complete the dam on an angle of approximately 30 degrees. He proceeded with work under said verbal order, and, amongst other matters, constructed a rock wall as part of said work, all under the contract of December 15, 1919. In the latter part of December, owing to the lateness of the season, work was practically shut down until February, 1921, when the defendant notified plaintiff that he would proceed with the construction of the dam under the order of October 28, 1920, unless otherwise ordered. In the meantime, the Railroad Commission approved a plan to return to the straight line axis, and the defendant was ordered in writing to carry out the work on that line. He agreed to do so if work “beyond the lines called for by the original contract” should be paid for under the clause in the original contract providing for alterations, omissions, additions, or substitutions in the work. The plaintiff answered that it stood upon the terms of the contract. Meanwhile a controversy arose between the contractor and the company as to the most feasible manner and best method of completing the dam. The plaintiff advocated and had ordered completion on a straight line axis. The defendant had agreed to go ahead, but insisted that the work be completed on an angle of approximately 44 degrees to avoid the slide caused by

Much correspondence passed between the contractor and the company relating to the work and the manner in which it would be paid for. The defendant was constantly demanding from plaintiff an interpretation of the contract as to method of payment, if he proceeded with construction

The large sums of money involved in this action, and its consequent importance to the parties, led to a minute and comprehensive presentation of the case in the lower court. The trial judge visited and inspected the dam and the premises involved in the action. The evidence taken at the trial, which lasted many days, was brought here in a reporter’s transcript of more than 3,000 pages; the points and authorities of the respective parties cover many hundreds of printed pages, and the case was orally argued at length. Counsel, with indefatigable industry, have raised and presented their contentions from every conceivable point of view. Every point raised or remotely suggested by either side has received attention and consideration from the opposing side. Viewed, however, from any and every angle, the appeal presents but one question: Was the contract entered into between the plaintiff and the defendant for the construction of the dam terminated by agreement of the parties and the resulting order given by plaintiff to defendant on May 21, 1921, to complete the dam on an angle of 44 degrees? From our examination and understanding of this voluminous record, we are convinced that the contract was not so terminated and that the finding of the trial court that the defendant abandoned the contract is amply supported by the evidence, and that the judgment must be affirmed. The findings are not attacked beyond a suggestion that they are in part contradictory as to the question of abandonment. As appellant expressly states in his opening brief that “no reversal is sought upon that ground,” we will consider the point no further.

Appellant’s argument is that the proposed change to the 44-degree angle was unreasonable, and was such a radical change in the nature of construction that it could not have been supposed to have been in the minds of the parties at the time the agreement was entered into. The proposed change was unreasonable, he insists, because the required amount of excavation to be done by reason of the change was not bid upon by him, and the ground to be excavated was physically of a different character, more difficult and more costly to excavate. The trial court found that the completion of the dam on the angle of 44 degrees was the most economical, practical, and efficient method of completing the structure, and was a reasonable alteration of the contract plan. The evidence amply establishes the fact that it was more feasible, cheaper, and better to build the dam on the angle rather than on the straight line, and was a reasonable alteration of the original plans and specifications. It will be recalled in this connection that it was the appellant who first advocated that the work be completed on the angle of 44 degrees, in order to avoid the slide caused by the flood.

The whole course of dealing between the parties tends to destroy the contention of appellant. One of the noticeable features throughout the contract is the evident intention of the parties to vary the plan of construction of the dam if it were found beneficial or necessary. The essential feature of the contract was the construction of the dam. It is obvious that in a work of the nature and magnitude of the proposed construction, the highest engineering skill, even when exercised with utmost care, could not

In order to furnish contractors with bases for their bids for building the dam, it was necessary to assume certain quantities and lines. Appellant offered to do the work called for within these lines for a definite amount. For additional work within these lines, which the drawings on their face showed might be necessary, but the full extent of which could not be determined until the work progressed, he was to be paid at the unit prices fixed in the contract. But if the work fell outside the lines of the plans, he was to be paid cost, plus 12% per cent for profit, excluding overhead expense, for such extra work. The contract itself thus making specific provision “for additional depth of excavation beyond that specified,” and “for additional concrete work over the dam as specified,” and “for reasonable alterations, omissions, additions or substitutions,” tends further to support the view that the parties had the conditions which subsequently arose in their minds at the time

By his cross-complaint the appellant sought to recover from respondent the difference between the contract price for the work and cost to him plus 10 per cent. [2] The question whether or not the change from a straight line axis to an angle of 44 degrees was unreasonable and so radically material as to terminate the contract for the construction of the dam, and give appellant a right to recover in quantum meruit for the value of the work done, was one of fact. (Tribble v. Yakima Valley Transp. Co., 100 Wash. 589 , 595 [ 171 Pac. 544 ] ; Annapolis etc. Co. v. Ross, 68 Md. 310 , 319 [ 11 Atl. 820 ].) The trial court has not only construed the contract as a matter of law contrary to appellant’s contention, but has also found, with ample support in the evidence, that the change ordered was a reasonable alteration under its terms. [3] Appellant was

[4] For another reason, appellant is not in position to question the order of May 21, 1921. The record is uncontradicted that he not only suggested the change from the straight line axis to an angle of 44 degrees, which was adopted by the respondent, but agreed to and accepted the order given him to complete the structure in that way. Appellant began exploratory work for the purpose of locating the foundations for the dam within the new lines. The answer to his contention that no written instruction was received by him is that he agreed to wait for the order in writing from the respondent to do the work until the Railroad Commission should give its consent for the location of the work within the new lines. Later, when asked if he would proceed provided the written order was given, he said he would not continue work under the contract at all. The law does not require an idle act. (Civ. Code, see. 3532.) [5] The provision in the contract that the respondent should direct alterations and substitutions in the work only by written order was for the benefit of the contractor and could be waived by him. (Enterprise Hotel Co. v. Book, 48 Or. 58 , 64 [ 85 Pac. 333 ] ; Cowles v. United Slates Fidelity & Guar. Co., 32 Wash. 120 , 126 [ 98 Am. St. Rep. 838 , 72 Pac. 1032 ].) [6] The finding that the appellant accepted and acted upon the verbal order to cease to perform further work in and about the construction of the dam on the straight line axis, and to complete the work on the angle of approximately 44 degrees, was expressly requested by appellant, and was made by the court at his instance. He is now estopped from challenging a finding made at his request. (National Loan & Inv. Co. v. Rockland Co., 94 Fed. 335 , 336 [ 36 C. C.

[7] Appellant contends that when the respondent served notice of election on June 30, 1921, whereby it elected to take over the equipment of appellant, and followed that notice by commencing this action and obtaining an injunction restraining appellant from continuing the work, which, he alleges, he was then doing under the contract, it was the respondent and not appellant that broke the agreement between the parties. He argues that there was never any threat on his part to quit the work, except a conditional threat which he asserts is meaningless in law, and which he also maintains he had a right to make, for it involved a mere proposition of compromise on his part. These considerations derive importance, he asserts, because of the fact that he did not abandon his contract but remained at work, and that, therefore, respondent’s election to take over the equipment and the institution of the suit for a restraining order were a breach by respondent of a still valid and existing contract. We are not impressed with appellant’s argument on this point. It would have more convincing weight if he had not so readily contented himself with the situation at the time. He made no effort on the hearing of the order to show cause to show that the restraining order had been improvidently granted, or to resist the granting of the temporary injunction which only went to the length of preventing him from removing his equipment and supplies from the dam and from interfering with respondent in taking over and using the same. He stipulated that it be granted. The reason he did so is quite apparent. He himself had declared the contract “dead.” His contention was that any further work would

[9] The clause of the contract giving respondent authority to take over appellant’s equipment and to proceed to complete the dam provides that “if the contractor fails to diligently prosecute said work in every particular, or if he shall abandon the work, or any part thereof, or shall fail in any way to perform the conditions of this agreement on his part to be performed, or shall become insolvent, or make an assignment or commit an act of bankruptcy, the company shall have the right, if it so elect, to take over all tools, equipment and supplies of the contractor . . . and proceed to complete the work.” There was ample authority in this provision for the respondent to proceed as it did. The appellant constantly claimed that the contract was terminated on May 21st because the order given him to complete the dam on the angle was unreasonable in that it called for work for which he claimed he would not be properly compensated, and that, therefore, the contract was terminated on that date. Having gone thus far, appellant is not in position to advance the inconsistent claim that the contract was in force at the time of the issuance of

The trial court found that on June 23d and continuously thereafter the appellant was insolvent. The respondent contends that it was an implied term of the contract that appellant would not permit himself, through insolvency, to be disabled from performing his contract, citing Central Trust Co. of Illinois (Trustee in Bankruptcy) v. Chicago Auditorium Assn., 240 U. S. 581 [ 60 L. Ed. 811 , L. R. A. 1917B, 580, 36 Sup. Ct. Rep. 412 , see, also, Rose’s U. S. Notes]. For this reason, it argues, it was justified in taking over the equipment. Whether this be so or not, or whether the insolvency of appellant prevented his completing the contract, it is unnecessary to decide. What we have already said disposes of the meritorious issues raised by the appeal.

The judgment'is affirmed.

Kerrigan, J., Lennon, J., Seawell, J., Law lor, J., Myers, J., and Wilbur, C. J., concurred.

Rehearing denied.